I.D.D.C Ltd – trading as The National Domelight Company
Terms and Conditions for the Supply of Goods and Services
The Customer's attention is particularly drawn to the provisions of clause 14 (Limitation of liability).
The following definitions and rules of interpretation apply in this agreement.
Business Day: a day other than a Saturday, Sunday, public holiday in England or within our 5 day shut down between the period 21 to 31 December depending on when the bank holiday falls each calendar year.
Commencement Date: has the meaning given in clause 2.2.
Conditions: these terms and conditions as amended from time to time in accordance with clause 19.8.
Contract: the contract between the Supplier and the Customer for the supply of Goods and/or Services in accordance with these Conditions.
Customer: the person or firm who purchases the Goods and/or Services from the Supplier.
Data Protection Legislation: the UK Data Protection Legislation and (for so long as and to the extent that the law of the European Union has legal effect in the UK) the GDPR and any other directly applicable European Union regulation relating to privacy.
Delivery Location: has the meaning given in clause 4.2.
Force Majeure Event: has the meaning given to it in clause 18.
GDPR: General Data Protection Regulation ((EU) 2016/679).
Goods: the goods (or any part of them) set out in the Order.
Goods Specification: any specification for the Goods, including any relevant plans or drawings, that are agreed by the Customer and the Supplier.
Intellectual Property Rights: patents, utility models, rights to inventions, copyright and [neighbouring and] related rights, trade marks, business names and domain names, rights in get-up, goodwill and the right to sue for passing off, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.
Order: the Customer's order for the supply of Goods and/or Services, as set out in the Customer's purchase order form, or the Customer's written acceptance of the Supplier's quotation, or overleaf, as the case may be.
Services: the services, including the Deliverables, supplied by the Supplier to the Customer as set out in the Service Specification.
Service Specification: the description or specification for the Services provided by the Supplier to the Customer.
Supplier: I.D.D.C Limited (trading as NDC Garage Doors and The National Domelight Company) registered in England and Wales with company number 02341977.
Supplier Materials: has the meaning given in clause 9.1(g).
UK Data Protection Legislation: any data protection legislation from time to time in force in the UK including the Data Protection Act 1998 or 2018 or any successor legislation.
(a) A person includes a natural person, corporate or unincorporated body (whether or not having separate legal personality).
(b) A reference to a party includes its successors and permitted assigns.
(c) A reference to a statute or statutory provision is a reference to it as amended or re-enacted. A reference to a statute or statutory provision includes all subordinate legislation made under that statute or statutory provision.
(d) Any words following the terms including, include, in particular, for example or any similar expression shall be construed as illustrative and shall not limit the sense of the words, description, definition, phrase or term preceding those terms.
(e) A reference to writing or written includes fax and email.
2. Basis of contract
2.1 The Order constitutes an offer by the Customer to purchase Goods and/or Services in accordance with these Conditions.
2.2 The Order shall be deemed accepted when the Supplier issues confirmation of acceptance of the Order, either by way of a ‘Deposit & Confirmation of Order Form’ or the issue of proforma invoice to the Customer, at which point and on which date the Contract shall come into existence (Commencement Date).
2.3 Any samples, drawings, descriptive matter or advertising issued by the Supplier and any descriptions of the Goods or illustrations or descriptions of the Services contained in the Supplier's catalogues or brochures are issued or published for the sole purpose of giving an approximate idea of the Services and/or Goods described in them. They shall not form part of the Contract or have any contractual force.
2.4 These Conditions apply to the Contract to the exclusion of any other terms that the Customer seeks to impose or incorporate, or which are implied by trade, custom, practice or course of dealing.
2.5 Any quotation given by the Supplier shall not constitute an offer, and is only valid for a period of 30 days from its date of issue.
2.6 All of these Conditions shall apply to the supply of both Goods and Services except where application to one or the other is specified.
3.1 The Goods are described in the Supplier's brochure; manufacturer’s brochure or as displayed on the Supplier’s website, as modified by any applicable Goods Specification.
3.2 To the extent that the Goods are to be manufactured in accordance with a Goods Specification supplied by the Customer, the Customer shall indemnify the Supplier against all liabilities, costs, expenses, damages and losses (including any direct, indirect or consequential losses, loss of profit, loss of reputation and all interest, penalties and legal costs (calculated on a full indemnity basis) and all other reasonable professional costs and expenses) suffered or incurred by the Supplier arising out of or in connection with any claim made against the Supplier for actual or alleged infringement of a third party's intellectual property rights arising out of or in connection with the Supplier's use of the Goods Specification. This clause 3.2 shall survive termination of the Contract. 3.3 To the extent that the Goods are to be manufactured in accordance with a Goods Specification supplied by the Customer, the Customer shall be obligated to provide the Supplier with sufficient accurate information, drawings and dimensions to enable the Supplier to perform the contract. The Supplier shall not be liable for any defect in Goods, which arise out of any failure or defect in the information provided by the Customer and the warranty contained herein shall not apply to such Goods.
3.4 The Supplier reserves the right to make a charge of £100.00 in addition to all incurred costs to the Customer for all or any changes in the type, specification, size, colour and any other changes to the Goods after the Supplier has received from the Customer a signed confirmation of order sheet or proforma invoice.
3.5 The Supplier reserves the right to amend the Goods Specification if required by any applicable statutory or regulatory requirement, and the Supplier shall notify the Customer in any such event.
3.6 The Customer is solely responsible in ensuring the Goods comply with relevant building regulations for their proposed use. If you require assistance contact our technical department on 01276 451555.
4. Delivery of Goods
4.1 The Supplier shall ensure that:
(a) each delivery of the Goods is accompanied by a delivery note which shows the date of the Order, the type and quantity of the Goods (including the code number of the Goods, where applicable), special storage instructions (if any) and, if the Order is being delivered by instalments, the outstanding balance of Goods remaining to be delivered; and
(b) it states clearly on the delivery note any requirement for the Customer to return any packaging material to the Supplier. The Customer shall make any such packaging materials available for collection at such times as the Supplier shall reasonably request. Returns of packaging materials shall be at the Supplier's expense. 4.2 The Supplier shall deliver the Goods to the location set out in the Order or such other location as the parties may agree (Delivery Location) at any time after the Supplier notifies the Customer that the Goods are ready.
4.3 Delivery of the Goods shall be completed on the completion of unloading of the Goods at the Delivery Location.
4.4 Any dates quoted for delivery of the Goods are approximate only, and the time of delivery is not of the essence. The Supplier shall not be liable for any delay in delivery of the Goods that is caused by a Force Majeure Event or the Customer's failure to provide the Supplier with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.
4.5 If the Supplier fails to deliver the Goods, its liability shall be limited to the costs and expenses incurred by the Customer in obtaining replacement goods of similar description and quality in the cheapest market available, less the price of the Goods. The Supplier shall have no liability for any failure to deliver the Goods to the extent that such failure is caused by a Force Majeure Event or the Customer's failure to provide the Supplier with adequate delivery instructions for the Goods or any relevant instruction related to the supply of the Goods.
4.6 The Supplier shall inform the Customer where off-loading assistance may be required in the event that the delivery is bulky and heavy in weight. The responsibility for arranging the off-loading assistance shall rest entirely with the Customer and in the event that unsuitable assistance is provided the Supplier may refuse delivery of the Goods.
4.7 If the Customer fails to accept delivery of the Goods within seven Business Days of the Supplier notifying the Customer that the Goods are ready, then except where such failure or delay is caused by a Force Majeure Event or by the Supplier's failure to comply with its obligations under the Contract in respect of the Goods:
(a) delivery of the Goods shall be deemed to have been completed at 9.00 am on the seventh Business Day following the day on which the Supplier notified the Customer that the Goods were ready; and
(b) the Supplier shall store the Goods until delivery takes place, and charge the Customer for all related costs and expenses (including insurance).
4.8 If 14 Business Days after the Supplier notified the Customer that the Goods were ready for delivery the Customer has not accepted delivery of them, the Supplier may resell or otherwise dispose of part or all of the Goods and, after deducting reasonable storage and selling costs, account to the Customer for any excess over the price of the Goods or charge the Customer for any shortfall below the price of the Goods.
4.9 The Supplier may deliver the Goods by instalments. Any delay in delivery or defect in an instalment shall not entitle the Customer to cancel any other instalment.
5. Quality of Goods
5.1 The Supplier warrants that on delivery, and for a period of 14 days from the date of delivery (warranty period), the Goods shall:
(a) conform in all material respects with the Goods Specification; and
(b) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979)
5.2 Subject to clause 5.3, the Supplier shall, at its option, repair or replace the defective Goods, or refund the price of the defective Goods in full if:
(a) the Customer gives notice in writing during the warranty period within a reasonable time of discovery that some or all of the Goods do not comply with the warranty set out in clause 5.1;
(b) the Supplier is given a reasonable opportunity of examining such Goods; and
(c) the Customer (if asked to do so by the Supplier) returns such Goods to the Supplier's place of business at the Customer’s cost.
5.3 The Supplier shall not be liable for the Goods' failure to comply with the warranty in clause 5.1 if:
(a) the Customer makes any further use of such Goods after giving a notice in accordance with clause 5.2;
(b) the defect arises because the Customer failed to follow the Supplier's oral or written instructions as to the storage, installation, commissioning, use or maintenance of the Goods or (if there are none) good trade practice;
(c) the defect arises as a result of the Supplier following any drawing, design or Goods Specification supplied by the Customer;
(d) the Customer alters or repairs such Goods without the written consent of the Supplier;
(e) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions; or (f) the Goods differ from the Goods Specification as a result of changes made to ensure they comply with applicable statutory or regulatory standards.
5.4 Except as provided in this clause 5, the Supplier shall have no liability to the Customer in respect of the Goods' failure to comply with the warranty set out in clause 5.1.
5.5 The terms of these Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.
6. Title and risk
6.1 The risk in the Goods shall pass to the Customer on completion of delivery.
6.2 Title to the Goods shall not pass to the Customer until the earlier of:
(a) the Supplier receives payment in full (in cash or cleared funds) for the Goods and any other goods that the Supplier has supplied to the Customer in respect of which payment has become due.
6.3 Until title to the Goods has passed to the Customer, the Customer shall:
(a) store the Goods separately from all other goods held by the Customer so that they remain readily identifiable as the Supplier's property;
(b) not remove, deface or obscure any identifying mark or packaging on or relating to the Goods;
(c) maintain the Goods in satisfactory condition and keep them insured against all risks for their full price on the Supplier's behalf from the date of delivery;
(d) notify the Supplier immediately if it becomes subject to any of the events listed in clause 14.2(b) to clause 14.2(d); and
(e) give the Supplier such information relating to the Goods as the Supplier may require from time to time.
6.4 Subject to clause 6.5, the Customer may resell or use the Goods in the ordinary course of its business (but not otherwise) before the Supplier receives payment for the Goods. However, if the Customer resells the Goods before that time:
(a) it does so as principal and not as the Supplier’s agent; and
(b) title to the Goods shall pass from the Supplier to the Customer immediately before the time at which resale by the Customer occurs.
6.5 If before title to the Goods passes to the Customer the Customer becomes subject to any of the events listed in clause 14.2(b) to clause 14.2(d), then, without limiting any other right or remedy the Supplier may have:
(a) the Customer's right to resell Goods or use them in the ordinary course of its business ceases immediately; and
(b) the Supplier may at any time:
(i) require the Customer to deliver up all Goods in its possession which have not been resold, or irrevocably incorporated into another product; and
(ii) if the Customer fails to do so promptly, enter any premises of the Customer or of any third party where the Goods are stored in order to recover them.
7. Supply of Services
7.1 The Supplier shall supply the Services to the Customer in accordance with the Service Specification in all material respects.
7.2 The Supplier shall use all reasonable endeavours to meet any performance dates for the Services specified, but any such dates shall be estimates only and time shall not be of the essence for the performance of the Services.
7.3 The Supplier reserves the right to amend the Service Specification if necessary to comply with any applicable law or regulatory requirement, or if the amendment will not materially affect the nature or quality of the Services, and the Supplier shall notify the Customer in any such event.
7.4 The Supplier warrants to the Customer that the Services will be provided using reasonable care and skill.
8.1 The Supplier will only be liable in respect of Services, including installation work, carried out by itself, it’s employees, agents or sub-contractors, but will not be liable in any case where there are direct contractual relations between the Customer and an installing party other than the Supplier.
8.2 The Supplier warrants that on installation, and for a period of 1 year from the date of installation (installation warranty period), the installation works shall:
(a) conform with the Service Specification; and
(b) be of satisfactory quality
8.3 Subject to clause 8.2, the Supplier shall, at its option, repair the defective installation if:
(a) the Customer gives notice in writing during the warranty period within a reasonable time of discovery that some or all of the Services do not comply with the warranty set out in clause 8.2;
(b) the Supplier is given a reasonable opportunity of examining such installation; and
8.4 The Supplier shall not be liable for the Goods' failure to comply with the warranty in clause 8.2 if:
(a) the defect arises because the Customer failed to follow the Supplier's oral or written instructions as to the storage, installation, commissioning, use or maintenance of the garage door or (if there are none) good trade practice;
(b) the defect arises as a result of the Supplier following any drawing, design or Goods Specification supplied by the Customer;
(c) the Customer alters or repairs the garage door without the written consent of the Supplier; or
(d) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions.
9. Customer's obligations
9.1 The Customer shall:
(a) ensure that the terms of the Order and any information it provides in the Service Specification and the Goods Specification are complete and accurate;
(b) co-operate with the Supplier in all matters relating to the Services;
(c) provide the Supplier, its employees, agents, consultants and subcontractors, with access to the Customer's premises, office accommodation and other facilities as reasonably required by the Supplier to provide the Services;
(d) provide the Supplier with such information and materials as the Supplier may reasonably require in order to supply the Services, and ensure that such information is complete and accurate in all material respects;
(e) prepare the Customer's premises for the supply of the Services;
(f) obtain and maintain all necessary licences, permissions and consents which may be required for the Services before the date on which the Services are to start;
(g) keep all materials, equipment, documents and other property of the Supplier (Supplier Materials) at the Customer's premises in safe custody at its own risk, maintain the Supplier Materials in good condition until returned to the Supplier, and not dispose of or use the Supplier Materials other than in accordance with the Supplier's written instructions or authorisation; and
(h) comply with any additional obligations as set out in the Service Specification and the Goods Specification.
9.2 If the Supplier's performance of any of its obligations under the Contract is prevented or delayed by any act or omission by the Customer or failure by the Customer to perform any relevant obligation (Customer Default):
(a) without limiting or affecting any other right or remedy available to it, the Supplier shall have the right to suspend performance of the Services until the Customer remedies the Customer Default, and to rely on the Customer Default to relieve it from the performance of any of its obligations in each case to the extent the Customer Default prevents or delays the Supplier's performance of any of its obligations;
(b) the Supplier shall not be liable for any costs or losses sustained or incurred by the Customer arising directly or indirectly from the Supplier's failure or delay to perform any of its obligations as set out in this clause 9.2; and
(c) the Customer shall reimburse the Supplier on written demand for any costs or losses sustained or incurred by the Supplier arising directly or indirectly from the Customer Default.
10. Charges and payment
10.1 The price for Goods: (a) shall be the price set out in the Order or, if no price is quoted, the price set out in the Supplier's published price list as at the date of the order; and (b) shall be exclusive of all costs and charges of packaging, insurance, transport of the Goods.
10.2 The charges for Services:
(a) shall be the price set out in the Order or, if no price is quoted, the price set out in the Supplier’s published price list as at the date of the order.
10.3 The Supplier reserves the right to:
(a) increase the charges for the Services on an annual basis with effect from each anniversary of the Commencement Date in line with the percentage increase in the Retail Prices Index in the preceding 12-month period and the first such increase shall take effect on the first anniversary of the Commencement Date and shall be based on the latest available figure for the percentage increase in the Retail Prices Index;
(b) increase the price of the Goods, by giving notice to the Customer at any time before delivery, to reflect any increase in the cost of the Goods to the Supplier that is due to:
(i) any factor beyond the control of the Supplier (including foreign exchange fluctuations, increases in taxes and duties, and increases in labour, materials and other manufacturing costs);
(ii) any request by the Customer to change the delivery date(s), quantities or types of Goods ordered, or the Goods Specification; or
(iii) any delay caused by any instructions of the Customer in respect of the Goods or failure of the Customer to give the Supplier adequate or accurate information or instructions in respect of the Goods.
10.4 In respect of Goods, unless the Customer has an account with the Supplier the price of the Goods and any additional charges will be paid in full in cash on or before delivery, save that where Goods are to be installed by the Supplier, 50% of the price shall be paid when the order is placed and 50% shall be paid upon completion of the installation.
10.5 Where the Customer has an account with the Supplier, the price of the Goods/Services will be paid in full not later than the 20th day of the calendar month following the date of the invoice.
10.6 The Supplier shall be entitled to close any account at any time at the Supplier’s sole discretion. In that event, the balance of the account becomes payable forthwith.
10.7 All amounts payable by the Customer under the Contract are exclusive of amounts in respect of value added tax chargeable from time to time (VAT). Where any taxable supply for VAT purposes is made under the Contract by the Supplier to the Customer, the Customer shall, on receipt of a valid VAT invoice from the Supplier, pay to the Supplier such additional amounts in respect of VAT as are chargeable on the supply of the Services or Goods at the same time as payment is due for the supply of the Services or Goods.
10.8 If the Customer fails to make a payment due to the Supplier under the Contract by the due date, then, without limiting the Supplier's remedies under clause 15 (Termination), the Customer shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause 10.8 will accrue each day at 4.5% a year above the Bank of England's base rate from time to time, but at 4.5% a year for any period when that base rate is below 0%.
10.9 All amounts due under the Contract shall be paid in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).
11. Intellectual property rights
11.1 All Intellectual Property Rights in or arising out of or in connection with the Services (other than Intellectual Property Rights in any materials provided by the Customer) shall be owned by the Supplier.
11.2 The Customer grants the Supplier a fully paid-up, non-exclusive, royalty-free non-transferable licence to copy and modify any materials provided by the Customer to the Supplier for the term of the Contract for the purpose of providing the Services to the Customer.
12. Data protection and data processing
12.1 Both parties will comply with all applicable requirements of the Data Protection Legislation. This clause 12 is in addition to, and does not relieve, remove or replace, a party's obligations under the Data Protection Legislation. In this clause 12, Applicable Laws means (for so long as and to the extent that they apply to the Supplier) the law of the European Union, the law of any member state of the European Union and/or Domestic UK Law; and Domestic UK Law means the UK Data Protection Legislation and any other law that applies in the UK.
12.2 The parties acknowledge that for the purposes of the Data Protection Legislation, the Customer is the data controller and the Supplier is the data processor (where Data Controller and Data Processor have the meanings as defined in the Data Protection Legislation).
13.1 Each party undertakes that it shall not at any time during the Contract, and for a period of five years after termination of the Contract, disclose to any person any confidential information concerning the business, affairs, customers, clients or suppliers of the other party, except as permitted by clause 13.2.
13.2 Each party may disclose the other party's confidential information:
(a) to its employees, officers, representatives, subcontractors or advisers who need to know such information for the purposes of carrying out the party's obligations under the Contract. Each party shall ensure that its employees, officers, representatives, subcontractors or advisers to whom it discloses the other party's confidential information comply with this clause 13; and
(b) as may be required by law, a court of competent jurisdiction or any governmental or regulatory authority.
13.3 Neither party shall use the other party's confidential information for any purpose other than to perform its obligations under the Contract.
14. Limitation of liability: THE CUSTOMER'S ATTENTION IS PARTICULARLY DRAWN TO THIS CLAUSE.
14.1 The Supplier has obtained insurance cover in respect of its own legal liability for claims not exceeding £5,000,000.00 per calendar year. The limits and exclusions in this clause reflect the insurance cover the Supplier has been able to arrange and the Customer is responsible for making its own arrangements for the insurance of any excess loss.
14.2 Nothing in the Contract limits any liability which cannot legally be limited, including liability for:
(a) death or personal injury caused by negligence;
(b) fraud or fraudulent misrepresentation; and
(c) breach of the terms implied by section 12 of the Sale of Goods Act 1979 or section 2 of the Supply of Goods and Services Act 1982 (title and quiet possession).
14.3 Subject to clause 14.2, the Supplier's total liability to the Customer shall not exceed £5000.00. The Supplier's total liability includes liability in contract, tort (including negligence), breach of statutory duty, or otherwise, arising under or in connection with the Contract.
14.4 The Supplier has given commitments as to compliance of the Goods and Services with relevant specifications in clause 5 clause 7. In view of these commitments, the terms implied by sections 13 to 15 of the Sale of Goods Act 1979 and sections 3 and 5 of the Supply of Goods and Services Act 1982 are, to the fullest extent permitted by law, excluded from this agreement.
14.5 Unless the Customer notifies the Supplier that it intends to make a claim in respect of an event within the notice period, the Supplier shall have no liability for that event. The notice period for an event shall start on the day on which the Customer became, or ought reasonably to have become, aware of the event having occurred and shall expire three months from that date. The notice must be in writing and must identify the event and the grounds for the claim in reasonable detail.
14.6 This clause 14 shall survive termination of the Contract.
15.1 Without affecting any other right or remedy available to it, either party may terminate the Contract with immediate effect by giving written notice to the other party if:
(a) the other party commits a material breach of its obligations under the Contract and (if such breach is remediable) fails to remedy that breach within 7 days after receipt of notice in writing to do so;
(b) the other party takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business [or, if the step or action is taken in another jurisdiction, in connection with any analogous procedure in the relevant jurisdiction];
(c) the other party suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or
(d) the other party's financial position deteriorates to such an extent that in the terminating party's opinion the other party's capability to adequately fulfil its obligations under the Contract has been placed in jeopardy.
15.2 Without affecting any other right or remedy available to it, the Supplier may terminate the Contract with immediate effect by giving written notice to the Customer if:
(a) the Customer fails to pay any amount due under the Contract on the due date for payment.
15.3 Without affecting any other right or remedy available to it, the Supplier may suspend the supply of Services or all further deliveries of Goods under the Contract or any other contract between the Customer and the Supplier if the Customer fails to pay any amount due under the Contract on the due date for payment, the Customer becomes subject to any of the events listed in clause 14.2(b) to clause 14.2(d), or the Supplier reasonably believes that the Customer is about to become subject to any of them.
16. Consequences of termination
16.1 On termination of the Contract:
(a) the Customer shall immediately pay to the Supplier all of the Supplier's outstanding unpaid invoices and interest and, in respect of Services and Goods supplied but for which no invoice has been submitted, the Supplier shall submit an invoice, which shall be payable by the Customer immediately on receipt;
(b) the Customer shall return all of the Supplier Materials and any Deliverables or Goods which have not been fully paid for. If the Customer fails to do so, then the Supplier may enter the Customer's premises and take possession of them. Until they have been returned, the Customer shall be solely responsible for their safe keeping and will not use them for any purpose not connected with this Contract.
16.2 Termination of the Contract shall not affect any rights, remedies, obligations and liabilities of the parties that have accrued up to the date of termination, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination.
16.3 Any provision of the Contract that expressly or by implication is intended to have effect after termination shall continue in full force and effect.
17.1 The formation of condensation on the inner skin or between each glazing skin of a rooflight is dependant on environmental conditions such as humidity, internal and external ambient temperature and/or natural/mechanical air movement. The Supplier is therefore unable to give absolute guarantees on the non-occurrence of condensation on any of the Supplier’s Goods.
17.2 It is the Customer’s responsibility to ensure that any installation of polycarbonate or glass rooflights or roof lanterns are suitable for the specific purpose required and is in accordance with all current building regulations. The Supplier shall not be held liable for any loss or damage caused by the Customer’s failure to comply therewith.
18. Force majeure
Neither party shall be in breach of the Contract nor liable for delay in performing or failure to perform, any of its obligations under the Contract if such delay or failure result from events, circumstances or causes beyond its reasonable control.
19.1 Assignment and other dealings
(a) The Supplier may at any time assign, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights and obligations under the Contract.
(b) The Customer shall not assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any of its rights and obligations under the Contract.
(a) Any notice given to a party under or in connection with this agreement shall be in writing and shall be:
(i) delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case); or
(b) Any notice shall be deemed to have been received:
(i) if delivered by hand, on signature of a delivery receipt or at the time the notice is left at the proper address; and
(ii) if sent by pre-paid first-class post or next working day delivery service, at 9.00 am on the Business Day after posting or at the time recorded by the delivery service; and
(c) This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.
If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal and enforceable. If such modification is not possible, the relevant provision or part-provision shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this clause shall not affect the validity and enforceability of the rest of the Contract.
A waiver of any right or remedy under the Contract or by law is only effective if given in writing and shall not be deemed a waiver of any subsequent right or remedy. A failure or delay by a party to exercise any right or remedy provided under the Contract or by law shall not constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict any further exercise of that or any other right or remedy. No single or partial exercise of any right or remedy provided under the Contract or by law shall prevent or restrict the further exercise of that or any other right or remedy.
19.5 No partnership or agency
Nothing in the Contract is intended to, or shall be deemed to, establish any partnership or joint venture between the parties, constitute either party the agent of the other, or authorise either party to make or enter into any commitments for or on behalf of the other party.
19.6 Entire agreement.
(a) The Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter.
(b) Each party acknowledges that in entering into the Contract it does not rely on, and shall have no remedies in respect of any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in the Contract. Each party agrees that it shall have no claim for innocent or negligent misrepresentation based on any statement in the Contract.
(c) Nothing in this clause shall limit or exclude any liability for fraud.
19.7 Third parties rights
(a) Unless it expressly states otherwise, the Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.
Except as set out in these Conditions, no variation of the Contract shall be effective unless it is agreed in writing and signed by the parties (or their authorised representatives).
19.9 Governing law
The Contract and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation shall be governed by and construed in accordance with the law of England and Wales.
Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.